Terms & Conditions

Enquire Now

"*" indicates required fields

Hidden
Hidden
Hidden

ANNEXURE 8 – 12 MONTH BUILD GUARANTEE
TERMS & CONDITIONS

Conditions of Eligibility

Your new home is eligible for the 12 month week build guarantee, if you meet the following eligibility criteria:

  • You have chosen to build one of WA Building Company’s standard single storey designs and have made little or no structural or design changes (less than 10% to any standard model);
  • You have signed up on WA Building Company’s Starter or Luxury promotion packages and have not added any extras, such as main floor tiling/flooring, internal wall painting, etc
  • Your home is to be constructed within the Perth Metropolitan Area of Western Australia; and
  • Your site is an ‘A’ Class site with a D10v footing classification, that is ready to build on and does not require extensive site works, including but not limited to; retaining walls, hard digging, rock breaking, bulk sand removal, etc.

Terms

Should you qualify, WA Building Company guarantees to complete the construction of your home within 12 months from Slab down. This timeframe does not include any temporary business closure periods (such as over Christmas). You will be notified of any temporary business closure periods in writing.

In the event that the course of construction is delayed by no fault of WA Building Company, your 12 month build guarantee will be voided and an extension of time will be implemented. Some of these faults may include but are not limited to:

  • An act of God;
  • Any pandemic related lockdowns, disruptions or shortages;
  • Any weather-related delays;
  • Any delay caused by you or a representative of you (such as your broker or your bank), including, but not limited to; failure to make payment, failure to provide selections or reselections, failure to provide WA Building Company with any requested information that is required and any site meetings that are delayed by you and/or your commitments;
  • Any delay caused by a supplier, including but not limited to; delivery delays, product shortages, products being discontinued and requiring a reselection or the supply of faulty or damaged goods; and
  • Theft or vandalism; any timeframe where construction was delayed due to theft or vandalism, will be excluded from this guarantee.

In the event that there is a disagreement about the quality and/or completion of works, that causes any delays to payment and/or construction, the build timeframe guarantee period will be put on hold until a resolution is reached. Should the resolution be in favour of you, your build guarantee period will recommence on the day of resolution and if the resolution is in favour of WA Building Company WA, the build guarantee will be voided.

Earthworks and other site preparations required prior to commencement of the build are not included in the 12 month build guarantee timeframe. The construction time will commence on the day that the slab progress claim is sent to you (Week 0) and construction will conclude on the day of ‘Practical Completion’, as defined in your building contract.

Should your Practical Completion Inspection (PCI) be delayed by no fault of WA Building Company WA, the building timeframe will cease on the true day of Practical Completion, as notified by the Builder.

Exclusive $0 Savings House & Land Packages’ and ‘No Lenders Mortgage Insurance

Terms And Conditions

The name of the promotion(s) is ‘$0 Savings House and Land Packages’ and ‘No Lenders Mortgage Insurance’
The offer is available to home buyers that are eligible for the WA State Government’s First Home Owners Grant incentive of $10,000.
Applicant/s must meet the lenders low deposit non-genuine savings criteria and is subject to lender approval
On signing a PPA (Preparation of Plans Agreement) a $1,500 deposit will be required to be paid to the builder.

Your full financial requirements need to be assessed by Axis Wealth Group Pty Ltd prior to any offer or acceptance of a loan product. Australian Credit Licence 484302

T&Cs apply, to approved applicants.

This offer may be withdrawn at any time without notice by discretion of WABC.

WA Building Company

‘WIN $21,000 Cash’ Promotion

Terms And Conditions

  1. Definitions
    • Applicant means a person eligible for the Promotion pursuant to clause 2 below.
    • Promotion means the competition to win $21,000.00.
    • Draw Date means 30 November https://www.wabuildingcompany.com.au/keystart/021.
    • Facebook Page means https://www.facebook.com/ads/experience/confirmation/?experience_id=978463019597189&is_responsive=0
    • Period means 1 September 2021 to 30 November 2021 inclusive.
    • PPA means a Preparation of Plans Agreement prepared by WABC with WABC and the Applicant as parties to that agreement.
    • Prize means $21,000.00 paid by way of electronic funds transfer into the nominated bank account of the winning Applicant.
    • Terms and Conditions means these terms and conditions for the Promotion.
    • WABC means Materon Investments WA Pty Ltd trading as WA Building Company (ACN 156 231 766).
    • Website means wabuildingcompany.com.au/win.
    • Winner means the winning Applicant of the Promotion.
  2. Eligibility
    • To be eligible to win the Promotion, the Applicant must:
      • reside in Western Australia;
      • be at least 18 years of age;
      • not be the registered proprietor of a property in Western Australia unless that property is the subject of a PPA with WABC executed within the Period;
      • not be employed by WABC or be an immediate family member of a WABC employee;
      • submit a valid entry for the Promotion pursuant to clause 3 herein; and
      • have executed a PPA with WABC within the Period.
  3. Entry for Promotion
    • To enter into the Promotion, the Applicant must submit a completed Promotion entry form via the Website or the Facebook Page within the Period.
    • By entering the Promotion, the Applicant acknowledges and agrees that:
      • they are bound by these Terms and Conditions;
      • all information provided by the Applicant to WABC in the entry form for the Promotion is true and correct to the best of the Applicant’s knowledge and belief; and
      • WABC may use the information provided in the entry form to contact the Applicant for the purposes of this Promotion and marketing.
  4. Drawing of the Winner
    • A Winner shall be randomly drawn from the pool of the Applicants’ entries on the Draw Date.
    • WABC reserves the right to draw further entries on the Draw Date if the Winner fails to claim the Prize pursuant to clause 4 herein.
    • WABC will make all reasonable efforts to contact the Winner to inform them that they have won the Prize using the information provided by the Winner in their entry form.
    • The Winner must provide their bank account details to WABC in writing for the payment of the Prize within 3 days of the Draw Date.
    • WABC will pay the Prize to the Winner within 3 days of receipt of the Winner’s bank account details to the bank account advised by the Winner.
  5. Unclaimed Prize
    • If within 3 days of the Draw Date the Winner fails to notify WABC in writing of their bank account details for payment of the Prize, the Prize will be forfeited by the Winner and a new Winner will be declared by WABC pursuant to clause 4b.
    • WABC shall continue to declare further Winners pursuant to clause 5a until such time as the Prize is claimed by the Winner pursuant to clause 4.
  6. Privacy
    • By entering into this Promotion, the Applicant agrees to WABC using and disclosing the information provided by the Applicant in the entry form for the purposes of administering the Promotion (including disclosure to third parties assisting in the administration of the Promotion), contacting the Winner(s), announcing the Winner(s) and/or for any purpose established in WABC’s privacy policy available at: https://www.wabuildingcompany.com.au/privacy-policy/.
    • Without in any way limiting the terms of these Terms and Conditions, the Applicant acknowledges and agrees to the terms of WABC’s privacy policy available at the website expressed at clause 6a above.
    • The Winner consents to WABC using their name, likeness, image and/or voice in any form of media without remuneration for the purposes of promoting this Promotion and any similar such future promotions/competitions by WABC in perpetuity.
  7. General
    • WABC reserves the right to terminate the Promotion at any time and without notice.
    • In the event WABC terminates the Promotion, WABC shall:
      • notify that the Promotion has been cancelled on the Website;
      • destroy all entry forms submitted by the Applicants as soon as practicable; and
      • refrain from using the information provided in the entry forms by the respective Applicant for the purposes of marketing unless that Applicant has otherwise agreed to their contact details being used for the purposes of marketing by WABC.
    • WABC reserves the right to amend, vary, modify or change these Terms and Conditions without notice.
    • WABC reserves the right to exclude any Applicant from the Promotion if WABC reasonably considers that, at its absolute discretion, the Applicant has breached these Terms and Conditions.
    • To the fullest extent permitted by law, WABC shall not be liable for any loss or damage whatsoever sustained by the Applicant arising from the operation of these Terms and Conditions.
    • WABC reserves the right to assign, novate and/or transfer all of its rights under these Terms and Conditions at its absolute discretion.
    • Any tax liability arising as a result of the Applicant receiving the Prize shall be the liability of the Applicant solely.
    • The Applicant acknowledges that they have had an opportunity to seek independent legal, financial and other expert advice before agreeing to these Terms and Conditions.
    • The Applicant acknowledges that in accepting these Terms and Conditions that they have not relied on any representations or warranties about the Promotion except as provided in these Terms and Conditions.

Terms & Conditions – $45k Kickstarter Grant

The Federal Government has announced a $15,000 HomeBuilder stimulus package for new home builds, which is on top of the $10,000 First Home Owners Grant. Plus we’re also giving away $20,000 worth of premium upgrades. That’s a $45,000 Kickstarter boost for you! It’s for a limited time only so contact us today to see if you’re eligible.
Promotion not to be used in conjunction with any other promotion.
Promotion is subject to change at the discretion of Materon Investments Pty Ltd.
Materon Investments Pty Ltd reserves the right to alter or amend the conditions associated with this promotion.
The promotion is available on Luxury series range homes only. The promotion is not available to non-standard designs (one off’s)
To be eligible for this promotion you must be an Australian citizen/resident.
To be eligible for this promotion means you must enter a building contract with Materon Investments Pty Ltd.
To be eligible for this promotion you must be eligible for finance.
The home must be constructed in a locality approved by Materon Investments Pty Ltd within the Perth metro area.
On signing a PPA (Preparation Of Plans Agreement) that a $1500 deposit will be required.
The F.H.O.G. does form part of the Builders Promotion. And is a separate government incentive.
Promotion is for a limited time determined by the sole discretion of Materon Investments Pty Ltd.
The builder may use discretion as to whether the promotion is to be extended or continued.
(It is the sole discretion of Materon Investements that any promotion at any given time by Materon Investements, is only available to new clients in the month of promotion.)
If you don’t qualify for the first home owners grant you still maybe eligible for $20,000 worth of Inclusions to the home.
The Owner agrees that neither the Builder nor its employees or agents are liable for the Owner failing to be eligible for, or receive any government grants, concessions or rebates of any kind (whether offered by state government, federal government or other instrumentality). The Owner warrants that it has either sought its own legal advice, or has had the opportunity to seek its own legal advice, in relation to any application to receive, and their eligibility to apply for, any government grant, concession or rebate, and has not relied on any representation (express or implied) by the Builder concerning the Owner’s eligibility.

Terms & Conditions – 75k Kickstarter Grant

The Federal Government has announced a $25,000 HomeBuilder stimulus package for new home builds, plus the State Government is offering a further $20,000 Building Bonus, which is on top of the $10,000 First Home Owners Grant. Plus we’re also giving away $20,000 worth of premium upgrades. That’s a $75,000 Kickstarter boost for you! It’s for a limited time only so contact us today to see if you’re eligible.
Promotion not to be used in conjunction with any other promotion.
Promotion is subject to change at the discretion of Materon Investments Pty Ltd.
Materon Investments Pty Ltd reserves the right to alter or amend the conditions associated with this promotion.
The promotion is available on Luxury series range homes only. The promotion is not available to non-standard designs (one off’s)
To be eligible for this promotion you must be an Australian citizen/resident.
To be eligible for this promotion means you must enter a building contract with Materon Investments Pty Ltd.
To be eligible for this promotion you must be eligible for finance.
The home must be constructed in a locality approved by Materon Investments Pty Ltd within the Perth metro area.
On signing a PPA (Preparation Of Plans Agreement) that a $1500 deposit will be required.
The F.H.O.G. does form part of the Builders Promotion. And is a separate government incentive.
Promotion is for a limited time determined by the sole discretion of Materon Investments Pty Ltd.
The builder may use discretion as to whether the promotion is to be extended or continued.
(It is the sole discretion of Materon Investements that any promotion at any given time by Materon Investements, is only available to new clients in the month of promotion.)
If you don’t qualify for the first home owners grant you still maybe eligible for $20,000 worth of Inclusions to the home.

The Owner agrees that neither the Builder nor its employees or agents are liable for the Owner failing to be eligible for, or receive any government grants, concessions or rebates of any kind (whether offered by state government, federal government or other instrumentality). The Owner warrants that it has either sought its own legal advice, or has had the opportunity to seek its own legal advice, in relation to any application to receive, and their eligibility to apply for, any government grant, concession or rebate, and has not relied on any representation (express or implied) by the Builder concerning the Owner’s eligibility.

Terms & Conditions – 30k Kickstarter Grant

The 30k Kickstarter grant Promotion is made up of $10,000 first home buyers grant, $20,000 worth of upgrades to home totaling 30,000 in value.
Promotion not to be used in conjunction with any other promotion.
Promotion is subject to change at the discretion of Materon Investments Pty Ltd.
Materon Investments Pty Ltd reserves the right to alter or amend the conditions associated with this promotion.
The promotion is available on Luxury series range homes only. The promotion is not available to non-standard designs (one off’s)
To be eligible for this promotion you must be an Australian citizen/resident.
To be eligible for this promotion means you must enter a building contract with Materon Investments Pty Ltd.
To be eligible for this promotion you must be eligible for finance.

The home must be constructed in a locality approved by Materon Investments Pty Ltd within the Perth metro area.
On signing a PPA (Preparation Of Plans Agreement) that a $1500 deposit will be required.
The F.H.O.G. does form part of the Builders Promotion. And is a separate government incentive.
Promotion is for a limited time determined by the sole discretion of Materon Investments Pty Ltd.
The builder may use discretion as to whether the promotion is to be extended or continued.
(It is the sole discretion of Materon Investements that any promotion at any given time by Materon Investements, is only available to new clients in the month of promotion.)
If you don’t qualify for the first home owners grant you still maybe eligible for $20,000 worth of Inclusions to the home.

WA Building Company ‘Pay your rent while you build’ Promotion

The name of this promotion is ‘Pay your rent while you build’ (“the Promotion”).
The promoter of the Promotion is Materon Investments t/a WA Building Company (“Promoter”).
Promotion Period
The Promotion commences from 1st April 2018 and runs until 31st May 2018
Eligibility
To be eligible for the Promotion, a person must:
Be looking to build with WA Building Company; and
Successfully enter, or be about to successfully enter, into a building contract with WA Building Company, at a date after the commencement date of this Promotion and within the Promotion Period.
Should there be two or more persons that enter into one (1) contract with WA Building Company, for the purposes of the Promotion they are to be viewed as one client (and therefore only eligible to one payment of $10,000).
Payment
As part of the Promotion, WA Building Company will provide eligible persons with a $10,000 lump sum payment. This can occur via:
$10,000 being paid to a bank account nominated by the client at settlement
Termination
In the event the client subsequently terminates the building contract with WA Building Company, or does not enter into a building contract with WA Building Company, or WA Building Company cancels the contract due to a breach from the client, the client agrees, regardless of the reason of termination, to refund the full value of the Promotion to WA Building Company
Other
As part of the Promotion, WA Building Company will provide eligible persons with a $10,000 lump sum payment. This can occur via:
Applicants are encouraged to seek independent financial or legal advice.
The Promotion may be terminated by the Promoter at any time without notice. The Promoter reserves the right to otherwise change the Terms and Condition of the Promotion, without notice.

Terms and Conditions apply – From $349/week

Repayments are provided as a guide only and are quoted are after the reduction of the $10,000 first home owners grant. Weekly repayments of $349 based on house & land package price at the published Westpac Flexi First Loan rate of 5.89% current at time of printing and subject to change. A comparison rate of 6.22% applies. WARNING: This comparison rate is true only for the examples given and may not include all fees and charges. Different terms, fees or other loan amounts might result in a different comparison rate. Terms and conditions, fees and charges, and normal lending criteria apply. House and Land Packages are based upon available blocks at time of publication – Please note that not all blocks are sold by WA Building Company and will need to be purchased through the relevant land developer. Photos for illustration purposes only – elevations pictured may incur additional cost. Prices include an estimate for site costs that may change. Prices do not include stamp duty costs. Builders Registration Number 14539 WA Building Company is not a provider of finance or credit facilities. All finance information shown as provided by Outsource Financial Pty Ltd (ACL 384324). 20k bonus inclusions available on every home. Our Privacy Policy. Win Your Rent for 1 Year Terms and Conditions.

Crown Towers Promotion

1. The promoter is WA Building Company whose registered office is at 69 Challenge Blvd, Wangara, Perth, WA 6065
2. The competition is open to residents of Western Australia aged 18 years or over except employees of WA Building Company and their close relatives and anyone otherwise connected with the organisation or judging of the competition.
3. There is no entry fee and no purchase necessary to enter this competition.
4. By entering this competition, an entrant is indicating his/her agreement to be bound by these terms and conditions.
5. Route to entry for the competition and details of how to enter are via Facebook
6. Only one entry will be accepted per person. Multiple entries from the same person will only be allowed if shared with friends and only if that friend enters.
7. Closing date for entry will be 31st January 2020. After this date the no further entries to the competition will be permitted.
8. No responsibility can be accepted for entries not received for whatever reason.
9. The rules of the competition and how to enter are as follows: Entrant must provide details to all questions requested via the Messenger bot campaign via Facebook, to be eligible for a chance to win.
10. 10. The promoter reserves the right to cancel or amend the competition and these terms and conditions without notice in the event of a catastrophe, war, civil or military disturbance, act of God or any actual or anticipated breach of any applicable law or regulation or any other event outside of the promoter’s control. Any changes to the competition will be notified to entrants as soon as possible by the promoter.
11. The promoter is not responsible for inaccurate prize details supplied to any entrant by any third party connected with this competition.
12. The prize is as follows: 2 nights at the Crown Towers in a Premier King room overlooking the river. The package includes an Epicurean Breakfast for two adults, valet parking and a bottle of sparkling wine.
13. The prize is as stated and no cash or other alternatives will be offered. The prizes are not transferable. Prizes are subject to availability and we reserve the right to substitute any prize with another of equivalent value without giving notice.
14. Winners will be chosen at random from all entries received and verified by Promoter and or its agents
15. The winner will be notified by phone and/or email and/or DM on Facebook within 28 days of the closing date. If the winner cannot be contacted or do not claim the prize within 14 days of notification, we reserve the right to withdraw the prize from the winner and pick a replacement winner.
16. The promoter will notify the winner when and where the prize can be collected / is delivered.
17. The promoter’s decision in respect of all matters to do with the competition will be final and no correspondence will be entered into.
18. By entering this competition, an entrant is indicating his/her agreement to be bound by these terms and conditions.
19. The competition and these terms and conditions will be governed by Western Australian law and any disputes will be subject to the exclusive jurisdiction of the courts of Western Australia.
20. The winner agrees to the use of his/her name and image in any publicity material, as well as their entry. Any personal data relating to the winner or any other entrants will be used solely in accordance with current Australian data protection legislation and will not be disclosed to a third party without the entrant’s prior consent.
21. Entry into the competition will be deemed as acceptance of these terms and conditions.
22. This promotion is in no way sponsored, endorsed or administered by, or associated with, Crown Towers, Facebook, Instagram, Twitter or any other Social Network. You are providing your information to WA Building Company and not to any other party. The information provided will be used in conjunction with the following Privacy Policy found at
https://www.wabuildingcompany.com.au/privacy-policy/

Compare listings

Compare